HomeMy WebLinkAboutCC Resolution 10633 (ADA Wheelchair Ramp 1999/00)RESOLUTION NO. 10633
RESOLUTION OF AWARD OF CONTRACT FOR ADA WHEELCHAIR RAMP
CONSTRUCTION 1999/2000 TO LUCAS CONCRETE, INC. IN THE
AMOUNT OF $ 84,600.00
WHEREAS, on the 201h day of April, 2000, pursuant to due and legal
notice published in the manner provided by law, inviting sealed bids or proposals for the
work hereinafter mentioned, as more fully appears from the Affidavit of Publication
thereof on file in the office of the City Clerk of the City of San Rafael, California, the City
Clerk of said City did publicly open, examine, and declare all sealed bids or proposals for
doing the following work in said City, to wit:
"ADA WHEELCHAIR RAMP CONSTRUCTION 1999/2000"
PROJECT NO. 011-1412-181-8000
in accordance with the plans and specifications therefor on file in the office of said City
Clerk; and
WHEREAS, the bid of Lucas Concrete, Inc. at the unit prices stated in its
bid was and is the lowest and best bid for said work and said bidder is the lowest
responsible bidder therefor;
NOW, THEREFORE, IT IS HEREBY ORDERED AND RESOLVED
that the bid of Lucas Concrete, Inc. and the same is hereby accepted at said unit prices
and that the contract for said work and improvements be and the same is hereby awarded
to said Lucas Concrete, Inc. at the unit prices mentioned in said bid.
IT IS FURTHER ORDERED AND RESOLVED that the Mayor and the
City Clerk of said City be authorized and directed to execute a contract with Lucas
Concrete, Inc. for said work and to return the bidders bond upon the execution of said
contract.
BE IT FURTHER RESOLVED that the Director of Public Works is
hereby authorized to take any and all such actions and make changes as may be necessary
to accomplish the purpose of this resolution.
I, JEANNE M. LEONCINI, Clerk of the City of San Rafael, hereby
certify that the foregoing resolution was duly and regularly introduced and adopted at a
regular meeting of the Council of said City on Monday, the 15` day of May, 2000, by the
following vote, to wit:
AYES: COUNCILMEMBERS• Heller, Miller, Phillips & Mayor Boro
NOES: COUNCILMEMBERS: None
ABSENT: COUNCILMEM 3ERS: Cohen
JE E M. LEO CINI, City Clerk
I.
O O O� O O N O OO O O O O C
U,
OI -00001-- 69 OQQO600
tn-- 0NCO r- OO O O% tov
j -- 00 of c: v! O llO 2 -J vl 7 N r- 'IT c� r- (21
O EW^F
r- 'IT 00 r- C14 Kc �W< M OO to C4 vic«
N F- ^
O�En
I `O\
UQQ0W) en otn C7 En 0000000
W ca to.) ONOM00N H 0060000
U Oo00cV OO�00 °�'p-= OO vi 0000
CS O t7 W Vl N 'V' O V I- N ca O V) 00 0 0 m Vl
C vaa _ � � ^ cq cq 'pi Q iYi .'_% a rn N D N •-:
O
ca p o kn c Q
kn ca
0 0 0 0 0 0 0 C o 6 0 6 0 o C
0000000 a? 6 OOOOOOOG
0 0 0 0 0 0 0 c 0 C 0 0 C 6 0 C
U W¢ o 00006 U �¢ 000o6o0cee
Oa0N NN VlC
FO oo'Ir ¢� FO ri�MrNVM da
0 0
UAO� wp]O�
oOQ 0000000 az 0006C6o
c:2U sv 0000000 ' MU 0000000
�y.d E-" �OO kn0000 GM y 0060000
�Lj pOMo006 op 8 E 677 00�o000o
OO U�OM �00 V1M p.,p �.., U ON to tnON
Eis ::)R 00^ M^ A C rn N M�--
cn-.a: L1aC7
0000000 00006600 0000000
0000000 0 000000 00 0000
0 00000-:oovO�0IiOloc)0c) o
us 0000000 es 00 tom0�0o7tC 69 o0OCornp
010606ut V1 0-�--�0\ V1OM(! a ON00 •-•7N0
-a c'ic�Ko00cNd vi �^a avi-vdtmza, a 0ri0r- i- r- d
cc WQ _
N H F- U y H O
F 0 N F c o c F
0 Ln cC.� •` 7 U V
o rn 4 �a
lQQ 0000000 oMU 0000000 ov)U 0006600
0000000
c'�'U 6000000 Urn- nM�d-•0O >- 0o000vi6
0 3 E^ W OO tnoo C)C C Kyr„ F W E; V)
VIO00 N Oyn„ E"' W OCm5c)NCD
U o G z U C _ o �y 'z U_ ^ " U h z U
N^�^ cwt �- `r-- M- o-` C4
to c a
a v ri
> _ a� v� C7 v Ln.60000000 c o000000c cc coo
ootn000 o "' 0000�oott" 00 0000
O'o toN Vin EO `j CZr4r-77ut oc a pQ OOOO�
0000 V100N
4n ON O\ -� 7 ^ t/') Q 7 D\ n O � N to 0c Q (V Vl O CV M OC
Er M--� h U n Ew-H M N 0c 0 N P
.. 0 o N O 0
_ 7
C E U >
C y y> Q C a) a
WW 0000000 0- 0000000 u b90000000
FW
o0Co--UEoF'� WU p o.-. ooW)oa 0pp000�00kno 7nrnM Z orn
NVlto , Mc 7
N Vl O O N
MC
L4 s� a Q a� ca 0.
C7 N V] > O
w� ^MNc O`^tn En ^c�nOO`O`- n Ln F- cq M kr)
L L L
F EnQu.QQlnQ v�Qk QQrnQ F V�Qfi QQLQ
- w ww.aW-aW.aWW.aW .aW-aWW.aW
01 L C O� •C C a y C
a 0 � a n •a a n •o
0 o Q c o Q c o Q
u oc o u o E o u o S o
0 Hb
^ ca > ca c�. .� �bc3 w ca a>•ca
Coom-vjC o y C o D]
p op w U y rn op CZ rn .U+ p�0 rn V y w
U, t o U c U, o ° U c U .i o ° U E S
p,00N Q a)U a) c a00N O. NU U 0 C% 00 G N U U n
. c 2 E? bt x E r, c n b< SG E rti c E a W2 E
cq N N ca c .+ ca cq N Nc1 c m cq N N ca C .+ ca
P: EW c PG E. •? n �= W 0.S ,.p W G1G F.. o fx
c� a�'G E- 0.4 c., c � ��T E"
c.�
=
L. rr a 0
co 3L
y x •y .� c. r. a N x •y .�
ea�Q aU cow M= card a CU caW ccarie hLU cIW aL
U C]>W U c-4 NU 0.1>Mu .C-4 NU M4> -M0
Up y Nes d Up Di ^ NaL =L N
n a� o U c a+ n O U6 v a+ o c � 0 a)
.0 z F O L iV ca O ca G C F O s (V ca O ca L C -I. C. O L cV cs o O L
3y 193--U�U3 3„ d 3--U U3 „ d �3--U U3
y •NM7tn�� I y NM7 V1z y NMV V1
Qac Fz dam �"� <am Fo
City of San Rafael • California
Form of Contract Agreement
For
ADA Wheelchair Ramp Construction 1999/2000
This Agreement is made and entered into this 1st day of May, 2000 by and between the
City of San Rafael (hereinafter called City) and Lucas Concrete, Inc. (hereinafter called
Contractor). Witnesseth, that the City and the Contractor, for the considerations
hereinafter named, agree as follows:
II - Scope of the Work
The Contractor hereby agrees to furnish all of the materials and all of the equipment
and labor necessary, and to perform all of the work shown on the plans and described
in the specifications for the project entitled: ADA Wheelchair Ramp Construction
1999/2000, all in accordance with the requirements and provisions of the Contract
Documents as defined in the General Conditions which are hereby made a part of this
Agreement.
III- Time of Completion
(a) The work to be performed under this Contract shall be commenced within five (5)
calendar days after the date of written notice by the City to the Contractor to
proceed.
(b) The work shall be completed within thirty (30) working days after the date of such
notice and with such extensions of time as are provided for in the General
Conditions.
IIII - Liquidated Damages
It is agreed that, if all the work required by the contract is not finished or completed
within the number of working days as set forth in the contract, damage will be
sustained by the City, and that it is and will be impracticable and extremely difficult to
ascertain and determine the actual damage which the City will sustain in the event of
and by reason of such delay; and it is therefore agreed that the Contractor will pay to
the City, the sum of $500 for each and every calendar day delay in finishing the work in
excess of the number of working days prescribed above; and the Contractor agrees to
pay said liquidated damages herein provided for, and further agrees that the City may
deduct the amount thereof from any moneys due or that may become due the
Contractor under the contract.
IV - The Contract Sum
The City shall pay to the Contractor for the performance of the Contract the
amounts determined for the total number of each of the units of work in the
following schedule completed at the unit price stated. The number of units
contained in this schedule is approximate only, and the final payment shall be
made for the actual number of units that are incorporated in or made necessary by
the work covered by the Contract.
�jF
ITEM
UNIT
EST
UNIT
ITEM
NO.
ITEM
QTY
PRICE, $
TOTAL, $
1
Mobilization
LS
1
2,000.00
2,000.00
2
Wheelchair Ramp Installation
I EA
36
1,100.00
39,600.00
3
12" PVC
LF
120
50.00
6,000.00
4
Catch Basin Type 'C'
EA
9
2,000.00
18,000.00
5
Modify Existing Catch Basin to
I EA
9
1,000.00
9,000.00
Manhole Top
6
Catch Basin, 6"PVC, concrete chuteI
LS
1
4,500.00
4,500.00
at the Kerner Blvd. location
7
Wheelchair Ramp installation c@i LosI
EA
5
1,100.00
5,500.00
Colindas Road, per Addendum No 1.
Grand
Total
$84,600.00
V - Progress Payments
(a). On not later than the 6th day of every month the Public Works Department shall
prepare and submit an estimate covering the total quantities under each item of
work that have been completed from the start of the job up to and including the
25th day of the preceding month, and the value of the work so completed
determined in accordance with the schedule of unit prices for such items together
with such supporting evidence as may be required by the City and/or Contractor .
(b). On not later than the 15th day of the month, the City shall, after deducting previous
payments made, pay to the Contractor 90% of the amount of the estimate as
approved by the Public Works Department.
(c). Final payment of all moneys due shall be made within 15 days after the expiration of
35 days following the filing of the notice of completion and acceptance of the work by
the Public Works Department.
(d). The Contractor may elect to receive 100% of payments due under the contract from
time to time, without retention of any portion of the payment by the public agency,
by depositing securities of equivalent value with the public agency in accordance
with the provisions of Section 4590 of the Government Code. Such securities, if
deposited by the Contractr, shall be valued by the City's Finance Director, whose
decision on valuation of the securities shall be final.
VI - Acceptance and Final Payment
(a) Upon receipt of written notice that the work is ready for final inspection and
acceptance, the Engineer shall within 5 days make such inspection, and when he
finds the work acceptable under the Contract and the Contract fully performed, he
will promptly issue a Notice of Completion, over his own signature, stating that the
work required by this Contract has been completed and is accepted by him under
the terms and conditions thereof, and the entire balance found to be due the
Contractor, including the retained percentage, shall be paid to the Contractor by
the City within 15 days after the expiration of 35 days following the date of
recordation of said Notice of Completion.
(b) Before final payment is due the Contractor shall submit evidence satisfactory to the
Engineer that all payrolls, material bills, and other indebtedness connected with
work have been paid, except that in case of disputed indebtedness or liens the
Contractor may submit in lieu of evidence of payment a surety bond satisfactory to
the City guaranteeing payment of all such disputed amounts when adjudicated in
cases where such payment has not already been guaranteed by surety bond.
AGREEMENT • 2
(c) The making and acceptance of the final payment shall constitute a waiver of all
claims by the City, other than those arising from any of the following: (1) unsettled
liens; (2) faulty work appearing within 12 months after final payment; (3)
requirements of the specifications; or (4) manufacturers' guarantees. It shall also
constitute a waiver of all claims by the Contractor, except those previously made
and still unsettled.
(d) If after the work has been substantially completed, full completion thereof is
materially delayed through no fault of the Contractor, and the Engineer so certifies,
the City shall, upon certificate of the Engineer, and without terminating the
Contract, make payment of the balance due for that portion of the work fully
completed and accepted.
Such payment shall be made under the terms and conditions governing final payment,
except that it shall not constitute a waiver of claims.
IN WITNESS WHEREOF, City and Contractor have caused their authorized
representatives to execute this Agreement the day and year first written above.
ATTEST:
Jeanne Moncini
City Clerk 1.
CITY OF SAN RAFAEL:
�lbe Boro
Mayor
APPO FORM: LUCAS CO RETE, INC•
�G�rG 7.ri
ry agghianti
City Attorney r
File No: 16.01.194
AGREEMENT •