Loading...
HomeMy WebLinkAboutCC Resolution 14392 (City Hall & TLCC Re-roof)RESOLUTION NO. 14392 A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF SAN RAFAEL ACCEPTING THE BID FROM SOUTHWEST CONSTRUCTION & PROPERTY MANAGEMENT IN THE AMOUNT OF $502,700, AND AUTHORIZING THE CITY MANAGER TO ENTER INTO A CONSTRUCTION CONTRACT FOR THE CITY HALL AND TERRA LINDA RECREATION CENTER ROOF REPLACEMENT PROJECT, CITY PROJECT NO. 11316, IN AN AMOUNT NOT TO EXCEED $583,950 WHEREAS, on the 18th day of September, 2017, pursuant to due and legal notice published in the manner provided by law, inviting sealed bids or proposals for the work hereinafter mentioned, as more fully appears from the Affidavit of Publication thereof on file in the office of the City Clerk of the City of San Rafael, California, the City Clerk of said City did publicly open, examine, and declare all sealed bids or proposals for doing the following work in said City, to wit: "City Hall and Terra Linda Recreation Center Roof Replacement" City Project No. 11316 in accordance with the plans and specifications therefore on file in the office of said City Clerk; and WHEREAS, the bid of $502,700 from Southwest Construction & Property Management at the unit prices stated in its bid, was and is the lowest and best bid for said work and said bidder is the lowest responsible bidder, and; WHEREAS, there is sufficient fund balance in the Building Maintenance Fund, Fund 603; and WHEREAS, an additional $270,000 shall be appropriated to City Project No. 11316 from Fund 603 for the purposes of this project. NOW, THEREFORE, THE CITY COUNCIL OF THE CITY OF SAN RAFAEL RESOLVES as follows: 1. The plans and specifications for the City Hall and Terra Linda Recreation Center Roof Replacement project, City Project No. 11316, on file in the office of the City Clerk, are hereby approved. 2. The bid of Southwest Construction & Property Management is hereby accepted at the unit prices stated in its bid. 3. The City Manager and the City Clerk are authorized and directed to execute the contract for the project, in a form approved by the City Attorney, with Southwest Construction & Property Management at the bid prices stated in its bid, and with a change order contingency amount of $81,500 (approximately 15 percent of the contract value) to address unforeseen conditions and other changes requested by the contractor or required by the City, and to return the bidder's bond upon the execution of the contract. 4. The City Council approves and appropriates $583,950 in the Building Fund (#603) to cover the expenses for this project, which includes the change order contingency. Change orders may be administered and approved by the Department of Public Works Director or his expressed designee. 5. The City Manager is hereby authorized to take any and all such actions and make changes as may be necessary to accomplish the purpose of this resolution. I, ESTHER C. BEIRNE, Clerk of the City of San Rafael, hereby certify that the foregoing resolution was duly and regularly introduced and adopted at a regular meeting of the City Council of said City held on Monday, the 18th day of September, 2017 by the following vote, to wit: AYES: COUNCILMEMBERS: Bushey, Colin, Gamblin, McCullough & Mayor Phillips NOES: COUNCILMEMBERS: None ABSENT: COUNCILMEMBERS: None ESTHER C. BEIRNE, City Clerk City of San Rafael ♦ California Form of Agreement For City Hall and Terra Linda Recreation Center Roof Replacement City Project No. 11316 This Agreement is made and entered into this /$70 day of�CpTE t -f k, by and between the City of San Rafael (hereinafter called "City") and Southwest Construction & Property Management, a California corporation (hereinafter called "Contractor"). Witnesseth, that the City and the Contractor, for the considerations hereinafter named, agree as follows: I - Scope of the Work The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work described in the plans and specifications for the project entitled: City Hall and Terra Linda Recreation Center Roof Replacement, City Project No. 11316, all in accordance with the Specifications and Contract Documents dated August 18, 2017, which are hereby made a part of this Agreement. II- Time of Completion (a) The work to be performed under this Contract shall be commenced within Five (5) Working Days after the date of written notice by the City to the Contractor to proceed. (b) All work shall be completed, including all punchlist work, within Thirtv three (33) Working Days and with such extensions of time as are provided for in the General Provisions. III - Liquidated Damages It is agreed that, if all the work required by the contract is not finished or completed within the number of working days as set forth in the contract, damage will be sustained by the City, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which the City will sustain in the event of and by reason of such delay; and it is therefore agreed that the Contractor will pay to the City, the sum of $1,000 for each and every calendar day's delay in finishing the work in excess of the number of working days prescribed above; and the Contractor agrees to pay said liquidated damages herein provided for, and further agrees that the City may deduct the amount thereof from any moneys due or that may become due the Contractor under the contract. IV - The Contract Sum The City shall pay to the Contractor for the perforniance of the Contract the amounts detennined for the total number of each of the units of work in the following schedule completed at the unit price stated. The number of units contained in this schedule is approximate only, and the final payment shall be made for the actual number of units that are incorporated in or made necessary by the work covered by the Contract. ITEM DESCRIPTION City Hall Roof Demolition and Replacement Terra Linda Roof Demolition and Replacement ESTIMATED UNIT QUANTITY LS UNIT PRICE u $363,600.00 = TOTAL PRICE $363,600.00 LS @ $139,10.00 = $139,100.00 GRAND TOTAL BID $502,700.00 V - Progress Payments (a) On not later than the 6th day of every month the Public Works Department shall prepare and submit an estimate covering the total quantities under each item of work that have been completed from the start of the job up to and including the 25th day of the preceding month, and the value of the work so completed determined in accordance with the schedule of unit prices for such items together with such supporting evidence as may be required by the City and or Contractor. (b) As soon as possible after the preparation of the estimate, the City shall, after deducting previous payments made, pay to the Contractor 951 o of the amount of the estimate as approved by the Public Works Department. Pagel of 3 L-1- I--]I� (c) The Contractor may elect to receive 100% of payments due under the contract from time to time, without retention of any portion of the payment by the public agency, by depositing securities of equivalent value with the public agency in accordance with the provisions of Section 22300 of the Public Contract Code. Such securities, if deposited by the Contractor, shall be valued by the City's Finance Director, whose decision on valuation of the securities shall be final. VI - Acceptance and Final Payment (a) Upon receipt of written notice that the work is ready for final inspection and acceptance, the Engineer shall within 5 days make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed, he will promptly issue a Notice of Completion, over his own signature, stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor by the City within 15 days after the expiration of 35 days following the date of recordation of said Notice of Completion. (b) Before final payment is due the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness or liens the Contractor may submit in lieu of evidence of payment a surety bond satisfactory to the City guaranteeing payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (c) Contractor shall provide a "Defective Material and Workmanship Bond" for 50% of the Contract Price, before the final payment will be made. (d) The making and acceptance of the final payment shall constitute a waiver of all claims by the City, other than those arising from any of the following: (1) unsettled liens; (2) faulty work appearing within 12 months after final payment; (3) requirements of the specifications; or (4) manufacturers' guarantees. It shall also constitute a waiver of all claims by the Contractor, except those previously made and still unsettled. (e) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer so certifies, the City shall, upon certificate of the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. VII - Assignment of Warranties; Waiver of Subrogation (a) Contractor hereby assigns to City all warranties, guarantees, or similar benefits such as insurance, provided by or reasonably obtainable from the manufacturers or suppliers of equipment, material or fixtures that Contractor has installed or provided in connection with the work performed tinder this Agreement. (b) Contractor hereby agrees to waive and arrange by contract for its subcontractors to waive any subrogation rights which any insurer of Contractor or its subcontractors might otherwise acquire in connection with the insurer's payment to Contractor or its subcontractors of any insured loss with respect to work performed under this Agreement. Contractor further agrees to obtain and to arrange for its subcontractors to obtain for City's benefit any endorsements from insurers that may be necessary to effect such waiver of subrogation. Specifically, any worker's compensation insurance policies of the Contractor or its subcontractors shall be endorsed with a waiver of subrogation in favor of City for any work performed by Contractor or its subcontractors under this Agreement, and copies of such endorsements shall be provided to City. IN WITNESS WHEREOF, City and Contractor have caused their authorized representatives to execute this Agreement the day and year first written above. Page 2 of 3 ATTEST: Esther C. Beirne City Clerk J D AS TO FORM: AEpsteinney File No.: 06.01.237 Page 3 of 3 CITY OF SAN RAFAEL: 7 ht;y..N z ager Southwest Construction & Property Management By: / Printed arae: IoLmeS T. Gar d in,e r Title o rporate Officer: \J Z Le �c�esi�en CONTRACT ROUTING FORM INSTRUCTIONS: Use this cover sheet to circulate all contracts for review and approval in the order shown below. TO BE COMPLETED BY INITIATING DEPARTMENT PROJECT MANAGER: Contracting Department: Public Works Project Manager: David Nicholson Extension: 3454 Contractor Name: Southwest Construction and Property Management Contractor's Contact: James Gardner Contact's Email: iames.eardner southWgq TpDm.com ❑ FPPC: Check if Contractor/Consultant must file Form 700 Step RESPONSIBLE DESCRIPTION COMPLETED REVIEWER DEPARTMENT DATE Check/Initial 1 Project Manager a. Email PINS Introductory Notice to Contractor 9/7/2017 ❑x DN 9/6/2017 b. Email contract (in Word) & attachments to City Atty c/o Laraine.Gittens@cityofsanrafael.org (] DIJ 2 City Attorney a. Review, revise, and comment on draft agreement 9/21/2017 ❑X LAG and return to Project Manager 9/21/2017 Q LAG b. Confirm insurance requirements, create Job on PINS, send PINS insurance notice to contractor 3 Project Manager Forward three (3) originals of final agreement to 9/22/2017 ❑X pl� contractor for their signature 4 Project Manager When necessary, * contractor -signed agreement ❑ N/A agendized for Council approval *PSA > $20,000; or Purchase > $35,000; or Or ,, I ®�N Public Works Contract > $125,000 9/18/2017 Date of Council approval PRINT CONTINUE ROUTING PROCESS WITH HARD COPY 5 Project Manager Forward signed original agreements to City 101411% Attorney with printed copy of this routing form 6 City Attorney Review and approve hard copy of signed 10 �I� 1 agreement 01 q �, 1), fl V -PQ V"� 7 City Attorney Review and approve insurance in PINS, and bonds (for Public Works Contracts) 8 City Manager/ Mayor Agreement executed by Council authorized official I 9 City Clerk Attest signatures, retains original agreement and ' forwards copies to Project Manager/3 .