HomeMy WebLinkAboutPW MMWD Hydrant Sprinkler Fireline Safety CenterMAR
IMUNICIPAL DISTRICT 20HYDRANT, PRI SPRINKLER EL NE AND WATER
INSTALLATION AGREEMENT �pY AREA
QtiC
THIS AGREEMENT is made and entered into this day of 2018, by
and between MARIN MUNICIPAL WATER DISTRICT, hereinafter called "District"; and, CITY OF
SAN RAFAEL hereinafter called "Applicant"; and, MAGGIORA & GHILOTTI INC. hereinafter called
"Contractor", as follows:
WHEREAS, Applicant has requested a hydrant installation, fireline connection, two water
service connections and the termination at the main of Service Nos. 00162, 00655, 00789 and 01067
to provide water service and fire protection 1375 Fifth Ave., San Rafael (APN: 011-205-01, 011-205-
17 & 011-205-04 — to be merged).
WHEREAS, District has determined that this request will require the installation of a 6 -inch
hydrant, 4 -inch fireline connection, 2 -inch service, 5/8 -inch service and termination at the main of
four existing service taps as per District's Standard Hydrant Drawing No. SD0003, Standard Fireline
Drawing No. SD0094, Standard Meter Connection Drawings, and other facilities as set forth in plans
prepared therefor.
NOW, THEREFORE, THE PARTIES HERETO AGREE AS FOLLOWS:
1. Installation Accordingto District Plans and Specifications: The installation applied
for and all work done in connection therewith shall be done under the supervision of and to the
satisfaction of District, and shall be installed in accordance with detailed plans and specifications or
supplemental plans as they may be prepared from time to time therefor by District. District shall
have absolute discretion in determining the kind and quality of the work and materials. As the work
progresses, District reserves and shall have the right to amend and adapt plans and specifications to
meet conditions as they develop. Any extra costs arising from any such revision of plans will be
charged to and paid for by Applicant.
ATTENTION IS CALLED TO THE STANDARD SPECIFICATIONS OF DISTRICT WHICH ARE
REFERRED TO AND ARE INCORPORATED HEREIN BY REFERENCE AS THOUGH SET FORTH AT
LENGTH. APPLICANT AGREES THAT ALL WORK SHALL BE DONE ACCORDING TO THE PROVISIONS
OF THE STANDARD SPECIFICATIONS AND THAT APPLICANT OR HIS SUBCONTRACTORS, IS FULLY
BOUND BY ALL PROVISIONS OF THE STANDARD SPECIFICATIONS.
2. Method of Performance of Work: Work done under this agreement shall be
performed as hereinafter indicated:
Items of Work:
Hydrant to be installed by .............. A
Fireline to be installed by .............. A
Service connections to be installed by .. „ .. A
Services to be terminated at the main by..... A
Methods of doing Work:
(A) Private contract to be let by Applicant.
s!
3. Estimated Cost of Work: The estimated cost of the facilities applied for as
determined by District is as follows:
Said cost estimates are made solely for the convenience of District in determining
required deposits, bonds, and guarantees. District makes no representations whatever, and assumes
no responsibility whatever, regarding the accuracy of said estimates.
4. Financial Arrangements to Be Made by the Applicant shall consist of the following:
Materials, Fees and Charges
The Applicant shall pay to the District the total estimated cost of Materials, Fees and
Charges set forth in Paragraph 3, Column 1, $31,131.
Installation Costs
Under Method A: The Applicant's contractor shall furnish a maintenance bond to the
District in the amount of $21,520 guaranteeing the cost of maintaining, repairing, or replacing the
facilities during the first two (2) years following completion of all facilities and acceptance by the
District.
The Contractor may substitute a check or certificate of deposit in a financial
institution satisfactory to District in lieu of a maintenance bond, provided the certificate may be
cashed by the District at any time at its option.
In addition, the Contractor shall furnish the following insurance requirements:
a. Workers' Compensation Insurance.
b. Public Liability - combined single limit of not less than $1,000,000.
c. Policy shall specifically name Marin Municipal Water District, its officers,
officials, agents, employees and volunteers as an additional insured and shall
provide that said coverage is primary to any insurance carried by the District.
d. A policy statement indicating that there shall be not less than 60 days written
notice prior to cancellation.
-2-
Column 1:
Column 2:
Column 3:
Materials,
Estimated
Fees, and
Installation
Charges
Costs
Total
Hydrant, Fireline & Services
$13,361
$86,080
$99,441
District Labor
$14,798
-
$14,798
District Equipment
$2,972
-
$2,972
TOTAL31
131
5K,.080
117 211
Said cost estimates are made solely for the convenience of District in determining
required deposits, bonds, and guarantees. District makes no representations whatever, and assumes
no responsibility whatever, regarding the accuracy of said estimates.
4. Financial Arrangements to Be Made by the Applicant shall consist of the following:
Materials, Fees and Charges
The Applicant shall pay to the District the total estimated cost of Materials, Fees and
Charges set forth in Paragraph 3, Column 1, $31,131.
Installation Costs
Under Method A: The Applicant's contractor shall furnish a maintenance bond to the
District in the amount of $21,520 guaranteeing the cost of maintaining, repairing, or replacing the
facilities during the first two (2) years following completion of all facilities and acceptance by the
District.
The Contractor may substitute a check or certificate of deposit in a financial
institution satisfactory to District in lieu of a maintenance bond, provided the certificate may be
cashed by the District at any time at its option.
In addition, the Contractor shall furnish the following insurance requirements:
a. Workers' Compensation Insurance.
b. Public Liability - combined single limit of not less than $1,000,000.
c. Policy shall specifically name Marin Municipal Water District, its officers,
officials, agents, employees and volunteers as an additional insured and shall
provide that said coverage is primary to any insurance carried by the District.
d. A policy statement indicating that there shall be not less than 60 days written
notice prior to cancellation.
-2-
5. Delay or Failure to Complete: If the District determines that there has been undue
delay in completion of any work to be performed, or a failure to complete the same within a
reasonable time, it may demand that Applicant forthwith either complete all such work or pay to
District the District's estimate of the entire amount required to complete all such work. District's
determination upon the question of undue delay or failure to complete shall be final and binding
upon Applicant. If Applicant fails to comply with said demand within a reasonable time, District may
take possession of all parts of the project and may complete it at the expense and for the account of
Applicant.
6. Payment of Actual Costs: Upon completion of installation of the facilities, District
will determine the actual amount of its costs and expenses thereby incurred. If the actual amount
exceeds the estimate previously paid, Applicant will pay to District the amount of such excess
promptly upon demand. If the actual amount is less than the estimate previously paid, District will,
upon completion and acceptance of the facilities, credit any excess money to any account then
owed by Applicant or refund it. District's determination of such costs and expenses shall be final
and binding provided that such determination shall be made upon the basis of generally accepted
accounting principles consistently applied and shall be free of arithmetical error. In the event a
bond, escrow, or certificate of deposit is being held, it likewise will be released to Applicant upon
acceptance of the work by District to the extent that it has not been used or required.
7. Right to Approve Contractor: District reserves the right to approve or disapprove of
the contractor or forces to be used and no installation may be made except by those approved by
District.
8. Applicant's Responsibility: Applicant shall take all responsibility for work under this
agreement; shall bear all cost or loss resulting to him or to District on account of the nature or
character of the work, or because of the nature of the ground in or on which the work is done is
different from what is assumed or expected; or on account of the weather, flood, earthquake,
landslide, subsidence, unforeseen difficulties, accidents, or any other causes; and he shall assume
the defense of, and indemnify and save harmless District and its officers, agents, and employees
from all claims of any kind arising from the performance of work under this agreement, including,
but not limited to, claims for personal injury, death, property damage, loss of use, and loss of
business, and including all such claims as may be asserted by officers, agents or employees of
Applicant, his contractors or subcontractors, District, or third parties.
Applicant agrees to provide in any contract entered into with any other party for the
performance of work under this agreement, that all work be done pursuant to terms of the Standard
Specifications of District, and that such other party indemnify and save harmless District and its
officers, agents, and employees from all claims of any kind arising from performance of said contract
or this agreement, including claims for personal injury, death, property damage, loss of use and loss
of business, and including all such claims as may be asserted by officers, agents, or employees of
Applicant, his contractors or subcontractors, District, orthird parties forfailure to so provide in any
contract let by Applicant.
The Applicant is required to obtain all permits required by the City of San Rafael.
9. Prevailing Wages: Pursuant to Section 1770 et seq of the Labor Code of the State of
California, the Contractor and all subcontractors under him shall pay not less than the prevailing
wage rate. The Contractor shall forfeit to the District a penalty, $25 for each laborer, workman, or
mechanic employed for each calendar day or portion thereof such laborer, workman, or mechanic is
paid less than the prevailing wage rate for any work done under this contract by him or by any
subcontractor under him. Contractor shall submit to the District completed certified payrolls on a
weekly basis.
3-
10. Furnishing of Materials: All materials except the above ground backflow assembly
will be supplied by District at District's Corporation Yard or Pipe Yard and at replacement cost with
allowance for overhead. Risk of loss of, or damage to materials shall pass to Applicant at the time
they are picked up from the District's Corporation Yard or Pipe Yard. Replacement cost will be based
on the "moving average unit price" method employed by District.
11. Inspection by District: Under Method A, District shall provide an inspectorto inspect
the installation of facilities. The cost of inspection shall be charged against the job. No part of the
facilities installed by Contractor shall be covered or obstructed until same has been inspected and
approved by the District inspector.
12. Acceptance: District assumes no obligation as to the ownership of the facilities
included in this agreement until such time as they are formally accepted. Applicant will be notified
in writing of acceptance of the work at such time as all facilities are satisfactorily installed in
accordance with the plans and specifications and all paving work is completed. Any cost incurred by
District necessitated by emergency or other repairs prior to final acceptance by District will be
charged against Applicant.
13. Title: Immediately upon acceptance, all right, title and interest in this installation and
all other facilities herein mentioned shall vest in District; except that the above ground backflow
assembly and all piping on the owner's side of the spool piece and bypass piping and fittings, shall
be owned and maintained by the owner of the property served. Upon activation of the fireline
connection, there will be a bimonthly standby charge in the amount of $76.35. Bimonthly service
and watershed management charges of $210.86 and $46.57 will apply for the 2 -inch and 5/8 -inch
meters, respectively. These charges are reviewed periodically and are subject to change.
14. Dispute Resolution: Any dispute or claim in law or equity between District and
Applicant or Contractor arising out of this agreement, if not resolved by informal negotiation
between the parties, shall be mediated by referring it to the nearest office of Judicial Arbitration and
Mediation Services, Inc. (JAMS) for mediation. Mediation shall consist of an informal, non-binding
conference or conferences between the parties and the judge -mediator jointly, then in separate
caucuses wherein the judge will seek to guide the parties to a resolution of the case. If the parties
cannot agree to a mutually acceptable member from the JAMS panel of retired judges, a list and
resumes of available mediators numbering one more than there are parties will be sent to the
parties, each of whom will strike one name leaving the remaining name as the mediator. If more
than one name remains, JAMS arbitrations administrator will choose a mediator from the remaining
names. The mediation process shall continue until the case is resolved or until such time as the
mediator makes a finding that there is no possibility of resolution.
At the sole election of the District, any dispute or claim in law or equity between
District and Applicant or Contractor arising out of this agreement which is not settled through
mediation shall be decided by neutral binding arbitration and not by court action, except as
provided by California law for judicial review of arbitration proceedings. The arbitration shall be
conducted in accordance with the rules of Judicial Arbitration and Mediation Services, Inc. The
parties to an arbitration may agree in writing to use different rules and/or arbitrators.
15. Attorney's Fees: In the event of legal action by District to collect any sums due from
Applicant hereunder, the prevailing party shall be entitled to reasonable attorney's fees to be set by
the court.
16. Interest on Unpaid Accounts: Any monies owed the District shall begin accruing
interest sixty days after the first billing date. Said interest will be the rate District earns on its
investments plus one percent, but shall in no event exceed 10% per annum.
-4-
17. Time of the essence: Time is of the essence.
18. Non -transferable: This agreement applies onlyto the installation described and may
not be transferred to any other installation.
APPLICANT:
CITY OF SAN RAFAEL
1400 Fifth Ave.
San Rafael, CA 94901
By
_ Nl't"'-���-
((Nae and titl if applicable)
GF�
CONTRACTOR:
MAGGIORA & GHILOTTI INC
555 DuBois St.
San Rafael, 94901
Gaut' Ohow
BY It
(Name an title if apticable)
MARIN MUNICIPAL WATER DISTRICT:
Michael Ban, P.E., Manager
Environmental and Engineering Services Division
14.72
�p,� RAF,F!
a 2
� y0
'rY WITH t' y
CON TRACT ROUTING FORIM
RECEIVED
'► JUN 1 3 2010'
CITY ATT RNEY
INSTRUCTIONS: Use this cover sheet to circulate all contracts for review and approval in the order shown below.
TO BE COMPLETED BY INITIATING DEPARTMENT PROJECT MANAGER
Contracting Department: Public Works
Project Manager: Faby Guillen
Extension: 3435
Project Name: FSI lA�ri►C , Q �,
Contractor's Contact: Marin Municipal Water District
Contract's Email: cborhan@marinwater_com
Step
RESPONSIBI h
DEPARTMENT
DESCRIPTION
COMPI-1: TED DATE
REVIEWER
Initial
a (•.mail PINS Introductory Notice to Contractor
b Email Contract (in Word) & attachments to City Attorney c/o
1
Project Manager
Laraine.Gittens@citvol*satiralacl.org cilvofsanral'aeLorg
6/8/2018
fg
a. Review, revise and continent on draft agreement and return to Project
/ )I
4
/-,Z,/
Z
/.?Manager
( / /
b. Confirm insurance requirements, creatc.lob on PINS, send PINS
G �IZ �I�
2
Cil Attorney
Cityy
insurance notice to contractor I`t/'
Forward three (3) originals of final agreement to contractor for ,eir
3
Project Manager
signature
When necessary, * contractor -signed agreement agendized for Council
approval
* PSA - 320,000 or Purchase > $35,000: or Public Works Contract
4
Project Manager
$125,000
PR IN I
CONTINUE ROUTING PROCESS Wrrl l I IARD COPY
Forward signed original agreement to City Attorney with printed copy of
5
6
Project Manager
City Attorney
this routing form
Review and approve hard copy of signed agreement
7
City Attorney
Review and approve insurance in PINS, and bonds (tor pulh works
contracts) �yNN//
8
City
Manager/Mayor
Agreement executed by Council authorized official
9
City Clerk
Attest signatures, retains original agreement and forwards copies to
project manager
lX
10
Project Manager
Forward Final Copy to Contractor
as
r
IV:X 1-1v