Loading...
HomeMy WebLinkAboutCC Resolution 14545 (2017 Storm Damage Repair - 80 Upper Toyon Drive)RESOLUTION NO. 14545 RESOLUTION OF THE SAN RAFAEL CITY COUNCIL AWARDING, AND AUTHORIZING THE CITY MANAGER TO EXECUTE, A CONSTRUCTION AGREEMENT FOR THE 2017 STORM DAMAGE REPAIR AT #80 UPPER TOYON DRIVE TO MAGGIORA & GHILOTTI, INC., IN THE AMOUNT OF $259,259; AND AUTHORIZING CONTINGENCY FUNDS IN THE AMOUNT OF $30,741 FOR A TOTAL APPROPRIATED AMOUNT OF $290,000. WHEREAS, on the 6th day of June 2018, pursuant to due and legal notice published in the manner provided by law, inviting sealed bids or proposals for the work hereinafter mentioned, as more fully appears from the Affidavit of Publication thereof on file in the office of the City Clerk of the City of San Rafael, California, the City Clerk of said City did publicly open, examine, and declare all sealed bids or proposals for doing the following work in said City, to wit: “2017 Storm Damage Repair - #80 Upper Toyon” City Project No. 11329 in accordance with the plans and specifications therefore on file in the office of the City Clerk; and WHEREAS, the bid of $259,259.00 from Maggiora & Ghilotti, Inc., at the unit prices stated in its bid, was and is the lowest and best bid for said work and said bidder is the lowest responsible bidder; and WHEREAS, staff has recommended that the project budget include a contingency amount of $30,741.00; and WHEREAS, the Council finds that this project is for the repair of an existing facility that is categorically exempt from environmental review under the California Environmental Quality Act (“CEQA”, 14 Cal Code Regs §15301; NOW, THEREFORE, THE CITY COUNCIL OF THE CITY OF SAN RAFAEL RESOLVES as follows: 1. The plans and specifications for the 2017 Storm Damage Repair - #80 Upper Toyon, City Project No. 11329, on file in the office of the City Clerk, are hereby approved. 2. The bid of Maggiora & Ghilotti, Inc. is hereby accepted at the unit prices stated in its bid, and the contract for said work and improvements is hereby awarded to Maggiora & Ghilotti, Inc. at the stated unit prices. 3. The City Manager is authorized and directed to execute a contract with Maggiora & Ghilotti, Inc. for the bid amount, in the form attached hereto as Exhibit 1 and incorporated herein, subject to final approval as to form by the City Attorney, and to return the bidder’s bond upon the execution of the contract. 4. Funds for the project totaling $290,000, which includes the construction award amount and contingency, will be appropriated for City Project No. 11329, from the Gas Tax Fund #206. 5. The City Manager is hereby authorized to take any and all such actions and make changes as may be necessary to accomplish the purpose of this resolution. I, Lindsay Lara, Clerk of the City of San Rafael, hereby certify that the foregoing Resolution was duly and regularly introduced and adopted at a regular meeting of the City Council of said City held on Monday, the 16th day of July, 2018 by the following vote, to wit: AYES: COUNCILMEMBERS: Bushey, Colin, McCullough & Mayor Phillips NOES: COUNCILMEMBERS: None ABSENT: COUNCILMEMBERS: Gamblin LINDSAY LARA, City Clerk File No.: 16.11.46 City of San Rafael  California Form of Agreement for 2017 Storm Damage Repair - #80 Upper Toyon This Agreement is made and entered into this ___ day of ________ 2018 by and between the City of San Rafael (hereinafter called City) and Maggiora & Ghilotti, Inc.. (hereinafter called Contractor). Witnesseth, that the City and the Contractor, for the considerations hereinafter named, agree as follows: l - Scope of the Work The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work described in the specifications for the project entitled: 2017 Storm Damage Repair - #80 Upper Toyon, all in accordance with the requirements and provisions of the Contract Documents as defined in the General Conditions which are hereby made a part of this Agreement. The required additional insured coverage for City under contractor’s liability insurance policy shall be primary with respect to any insurance or coverage maintained by city and shall not call upon city’s insurance or self-insurance for any contribution. lI- Time of Completion (a) The work to be performed under this Contract shall be commenced within Five (5) Working Days after the date of written notice by the City to the Contractor to proceed. (b) All work shall be completed, including all punchlist work, within Forty (40) Working Days and with such extensions of time as are provided for in the General Provisions. llI - Liquidated Damages It is agreed that, if all the work required by the contract is not finished or completed within the number of working days as set forth in the contract, damage will be sustained by the City, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which the City will sustain in the event of and by reason of such delay; and it is therefore agreed that the Contractor will pay to the City, the sum of $500 for each and every calendar day’s delay in finishing the work in excess of the number of working days prescribed above; and the Contractor agrees to pay said liquidated damages herein provided for, and further agrees that the City may deduct the amount thereof from any moneys due or that may become due the Contractor under the contract. lV - The Contract Sum The City shall pay to the Contractor for the performance of the Contract the amounts de termined for the total number of each of the units of work in the following schedule completed at the unit price stated. The number of units contained in this schedule is approximate only, and the final payment shall be made for the actual number of units that are incorporated in or made necessary by the work covered by the Contract; provided that the total compensation under this Contract shall not exceed Two Hundred Fifty- Nine Thousand Two Hundred Fifty-Nine Dollars and 00/100 ($259,259.00) unless a written amendment is executed by the City and the Contractor. BASE BID ITEMS NO. ITEM QUANTI TY UNIT S UNIT PRICE TOTAL PRICE 1. Mobilization (3% of Base Bid) 1 LS $7,000.00 = $7,000.00 2. Signs and Traffic Control 1 LS $7,994.00 $7,994.00 3. Clearing and Grubbing 1 LS $18,375.00 $18,375.00 4. Cast in Drilled Hole (CIDH) Piles ** 60 LF $400.00 $24,000.00 5. Concrete Retaining Wall ** 30 CY $2,300.00 $69,000.00 6. Tieback Anchorsl** 170 LF $175.00 $29,750.00 7. Excavation ** 130 CY $350.00 $45,500.00 8. MSE Block Wall 165 SF $900.00 $14,850.00 9. ¾” Clean Crushed Drainrock 70 70 $160.00 $11,200.00 10. Mirafi 140N Filter Fabric 920 SF $2.00 $1,840.00 11. 6” Diameter Perforated Subdrain 100 LF $30.00 $3,000.00 12. Subdrain Cleanout 2 EA $1,000.00 $2,000.00 13. 6 Foot Conform Grind 1550 SF $60.00 $3,000.00 14. Hot Mix Asphalt 25 Ton $350.00 $8,750.00 15. Asphalt Berm 100 LF $35.00 $3,500.00 16. Timber Fence 50 LF $190.00 $9,500.00 BASE BID $259,259.00 V - Progress Payments (a) On not later than the 6th day of every month the Public Works Department shall prepare and submit an estimate covering the total quantities under each item of work that have been completed from the start of the job up to and including the 25th day of the preceding month, and the value of the work so completed determined in accordance with the schedule of unit prices for such items together with such supporting evidence as may be required by the City and/or Contractor . (b) As soon as possible after the preparation of the estimate, the City shall, after deducting previous payments made, pay to the Contractor 95% of the amount of the estimate as approved by the Public Works Department. (c) Final payment of all moneys due shall be made within 15 days after the expiration of 35 days following the filing of the notice of completion and acceptance of the work by the Public Works Department. (d) The Contractor may elect to receive 100% of payments due under the contract from ti me to time, without retention of any portion of the payment by the public agency, by depositing securities of equivalent value with the public agency in accordance with the provisions of Section 22300 of the Public Contract Code. Such securities, if deposited by the Contractor, shall be valued by the City’s Finance Director, whose decision on valuation of the securities shall be final. VI - Acceptance and Final Payment (a) Upon receipt of written notice that the work is ready for final inspection and acceptance, the Engineer shall within 5 days make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed, he will promptly issue a Notice of Completion, over his own signature, stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor by the City within 15 days after the expiration of 35 days following the date of recordation of said Notice of Completion. (b) Before final payment is due the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness or liens the Contractor may submit in lieu of evidence of payment a surety bond satisfactory to the City guaranteeing payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (c) Contractor shall provide a "Defective Material and Workmanship Bond" for 50% of the Contract Price, before the final payment will be made. (d) The making and acceptance of the final payment shall constitute a waiver of all claims by the City, other than those arising from any of the following: (1) unsettled liens; (2) faulty work appearing within 12 months after final payment; (3) requirements of the specifications; or (4) manufacturers’ guarantees. It shall also constitute a waiver of all claims by the Contractor, except those previously made and still unsettled. (e) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer so certifies, the City shall, upon certificate of the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. VII - Assignment of Warranties; Waiver of Subrogation (a) Contractor hereby assigns to City all warranties, guarantees, or similar benefits such as insurance, provided by or reasonably obtainable from the manufacturers or suppliers of equipment, material or fixtures that Contractor has installed or provided in connection with the work performed under this Agreement. (b) Contractor hereby agrees to waive and arrange by contract for its subcontractors to waive any subrogation rights which any insurer of Contractor or its subcontractors might otherwise acquire in connection with the insurer’s payment to Contractor or its subcontractors of any insured loss with respect to work performed under this Agreement. Contractor further agrees to obtain and to arrange for its subcontractors to obtain for City’s benefit any endorsements from insurers that may be necessary to effect such waiver of subrogation. Specifically, any worker’s compensation insurance policies of the Contractor or its subcontractors shall be endorsed with a waiver of subrogation in favor of City for any work performed by Contractor or its subcontractors under this Agreement, and copies of such endorsements shall be provided to City. IN WITNESS WHEREOF, City and Contractor have caused their authorized representatives to execute this Agreement the day and year first written above. ATTEST: CITY OF SAN RAFAEL: Lindsay Lara City Clerk Jim Schutz City Manager APPROVED AS TO FORM: CONTRACTOR: Rob Epstein City Attorney By: ____________________________________ [Print Name of Corporate Officer] _________________________________________ [Title of Corporate Officer] and _____________________________________ By: _____________________________________ [Print Name of Corporate Officer] _________________________________________ [Title of Corporate Officer]