Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
PW St. Resurfacing 2007-08 Project
Agenda Item No: 9 Meeting Date: August 4, 2008 SAN RAFAEL CITY COUNCIL AGENDA REPORT Department: Public Works Prepared by: �/ City Manager Approval: Director of P lic Works (DD) File No. 16.06.64 SUBJECT: REPORT OF BID OPENING AND RESOLUTION AWARDING THE CONTRACT FOR STREET RESURFACING 2007/2008, PROJECT NO. 11100, TO GHILOTTI CONSTRUCTION COMPANY, INC., IN THE AMOUNT OF $1,938,009.75 AND APPROVING THE STREETS DESIGNATED FOR RESURFACING. RECOMMENDATION: Adopt resolution. BACKGROUND: The Street Resurfacing 2007/2008 project targets 18 streets throughout the City of San Rafael for repaving. The list of streets to be resurfaced this year is attached to this report and totals approximately 4.83 miles. Bids for Street Resurfacing 2007/2008 were opened on July 22, 2008. ANALYSIS: The City had all of its streets evaluated in October and a five year maintenance list was established using the Street Saver Program approved by MTC. The streets have a Pavement Condition Index (PCI) from 9 to 65. Staff has also considered the feasibility of implementing locally defined bicycle and pedestrian improvements as part of the project. Where possible, roadway striping will be revised to accommodate bicycle paths. Curb ramps will be constructed on each corner. Fifty-six curb ramps will be installed or upgraded. They represent 10% of the total project cost. As a standard practice, engineering staff considers this multi -modal approach on all projects. In accordance with strategy 3.2 of the TAM Measure A Strategic Plan, the City Council is required to approve projects that are funded with Local Measure A funds at a public meeting. The following is a list of the Engineer's Estimate and the bids received: FOR CITY CLERK ONLY File No.: If-1-603�y/i (/-/S Council Meeting: 7 Lf/Og Disposition: Pf504-07(019/ 4-' 1254 ;� SAN RAFAEL CITY COUNCIL AGENDA REPORT / Page: 2 Engineer's Estimate $1,867,236.25 1. Ghilotti Construction Company, Inc. $1,938,009.75 (3.8%) 2. Ghilotti Bros., Inc. $2,115,439.50 (13.3%) 3. Team Ghilotti $2,149,735.73 (15.1%) 4. W.K. McLellan $2,268,077.34 (21.5%) 5. Argonaut Constructors $2,292,530.00 (22.8%) Refer to the attached Bid Summary Sheet for complete details on Unit and Total Prices of Items. FISCAL IMPACT: The total Droiected cost for this nroiect is as fnllnws- Cate o -Eden Expense Code Amount Note(s) Design -01 In-house. Construction -02 $2,034,910.00 Lowest bid, includes 5% contingency Construction Management -03 $50,000.00 Land Acquisition -04 $933,646.00 Site Testing -05 $10,000.00 Furniture and Equipment -06 Supplies and Services -07 Personnel -08 Construction Inspection -99 Total Projected Cost $2,094,910.00 We request that the Council approve $2,182,683.00 for the project, from the following funding source(s): Source Amount Note(s) Construction Vehicle Impact Fee $566,613.00 07-08 Allocation Local Measure A $503,904.00 08-09 Allocation Gas Tax $90,747.00 07-08 Allocation Proposition 1 B $933,646.00 Total Available Funds $2,094,910.00 OPTIONS: The Engineer's Estimate was $1,867,236.25. Ghilotti Construction Company, Inc., with a bid of $1,938,009.75, is the lowest and responsible bidder for this project. The City Council may reject all bids, but staff does not recommend this option, since the bids reviewed are very competitive and within 3.8% of the Engineer's Estimate. ACTION REQUIRED: Staff recommends that the City Council adopt the resolution awarding the contract to Ghilotti Construction Company, Inc. in the amount of $1,938,009.75 and approve the streets designated for resurfacing. Enclosures (3) 1. Bid Summary 2. Resolution 3. List of Streets to be Resurfaced RESOLUTION NO. 12547 RESOLUTION OF THE CITY COUNCIL OF THE CITY OF SAN RAFAEL AWARDING THE CONTRACT FOR STREET RESURFACING 2007/2008, PROJECT NO. 11100, TO GHILOTTI CONSTRUCTION COMPANY, INC., IN THE AMOUNT OF $1,938,009.75 AND APPROVING THE STREETS DESIGNATED FOR RESURFACING TO BE PARTIALLY FUNDED UTILIZING LOCAL MEASURE A FUNDS. WHEREAS, on the 22nd day of July, 2008, pursuant to due and legal notice published in the manner provided by law, inviting sealed bids for proposals for the work hereinafter mentioned, as more fully appears from the Affidavit of Publication thereof on file in the office of the City Clerk of the City of San Rafael, California, the City Clerk of said City did publicly open, examine, and declare all sealed bids or proposals for doing the following work in said City, to wit: "STREET RESURFACING 2007/2008" PROJECT NO. 11100 in accordance with the plans and specifications therefore on file in the office of said City Clerk; and WHEREAS, the streets designated for resurfacing are eligible to be funded utilizing Local Measure A funds; and WHEREAS, the bid of Ghilotti Construction Company, Inc. at the unit prices stated in its bid was and is the lowest and best bid for said work and said bidder is the lowest responsible bidder therefore. NOW, THEREFORE, IT IS HEREBY ORDERED AND RESOLVED that the Council approved the streets designated for resurfacing to be partially funded utilizing Local Measure A funds. RESOLVED FURTHER, that the bid of Ghilotti Construction Company, Inc. and the same is hereby accepted at said unit prices and that the contract for said work and improvements be and the same is hereby awarded to said Ghilotti Construction Company, Inc. at the unit prices mentioned in said bid. RESOLVED FURTHER, that the Mayor of said City be authorized and directed to execute a contract with Ghilotti Construction Company, Inc. for said work and to return the bidders bond upon the execution of said contract. RESOLVED FURTHER, that the Director of Public Works is hereby authorized to take any and all such actions and make changes as may be necessary to accomplish the purpose of this resolution. I, ESTHER C. BEIRNE, City Clerk of the City of San Rafael, hereby certify that the foregoing resolution was duly and regularly introduced and adopted at a regular meeting of the Council of said City held on the 4th day of August, 2008, by the following vote, to wit: AYES: COUNCIL MEMBERS: Brockbank, Connolly, Heller, Miller & Mayor Boro NOES: COUNCIL MEMBERS: None ABSENT: COUNCIL MEMBERS: None File No. 16.06.64 City of San Rafael ♦ California Form of Contract Agreement for Street Resurfacing 2007/2008 Project No: 11100 This Agreement is made and entered into this 4th day of August 2008 by and between the City of San Rafael (hereinafter called City) and Ghilotti Construction Company Inc. (hereinafter called Contractor). Witnesseth, that the City and the Contractor, for the considerations hereinafter named, agree as follows: II - Scope of the Work The Contractor hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work shown on the plans and described in the specifications for the project entitled: Street Resurfacing 2007/2008, Project No. 11100, all in accordance with the requirements and provisions of the Contract Documents as defined in the General Conditions which are hereby made a part of this Agreement. III- Time of Completion OA (a) The work to be performed under this Contract shall be commenced within 5 calendar days after the date of written notice by the City to the Contractor to proceed. (b) The work shall be completed within 45 working days after the date of such notice and with such extensions of time as are provided for in the General Conditions. IIII - Liquidated Damages It is agreed that, if all the work required by the contract is not finished or completed within the number of working days as set forth in the contract, damage will be sustained by the City, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which the City will sustain in the event of and by reason of such delay; and it is therefore agreed that the Contractor will pay to the City, the sum of $1.000 for each and every calendar day's delay in finishing the work in excess of the number of working days prescribed above; and the Contractor agrees to pay said liquidated damages herein provided for, and further agrees that the City may deduct the amount thereof from any moneys due or that may become due the Contractor under the contract. IV - The Contract Sum The City shall pay to the Contractor for the performance of the Contract the amounts determined for the total number of each of the units of work in the following schedule completed at the unit price stated. The number of units contained in this schedule is approximate only, and the final payment shall be made for the actual number of units that are incorporated in or made necessary by the work covered by the Contract. AGREEMENT 0 1 NO. ITEM QUANTITY UNITS UNIT PRICE TOTAL PRICE 8. A.C. Berm/Dike 2,303 LF (i{? 8.50 = $19,575.50 1. Mobilization 1 LS cid 150,100.00 = $150,100.00 2. Traffic Control 1 LS «; 16,000.00 = $16,000.00 11, 3. Asphalt Concrete Overlay 13,196 TON ri? 95.00 = $1,253,620.00 (Type A) 34 EA (ii? 375.00 = $12,750.00 4. Cold Planing 25,893 SY (r; 2.55 = $66,027.15 5. Deep Lift Patching 5 SY (r; 380.00 = $1,900.00 6. Fabric Reinforcement 57,265 SY (61? 1.74 = $99,641.10 7. Thermoplastic Traffic 7 EA y'r 215.00 = $1„505.00 Stripes, Pavement 24 EA (i` 215.00 = $5,160.00 Markings, & Delineators 1 LS til) 56 000 00 = $56 000 00 8. A.C. Berm/Dike 2,303 LF (i{? 8.50 = $19,575.50 9. Adjust Manhole Castings to Grade a. Sanitary Sewer 96 EA (u? 375.00 = $36,000.00 b. Storm Drain 34 EA (ii? 375.00 = $12,750.00 c. PG&E 10 EA (r? 375.00 = $3,750 00 d. Pac Bell 5 EA i 375.00 = $1,875.00 10. Adjust Castings to Grade a. Sewer Rodholes 7 EA y'r 215.00 = $1„505.00 b. Monuments 24 EA (i` 215.00 = $5,160.00 c. Water Valves 112 EA la? 105.00$11,760.00 ................ d.Traffic Detector Handhole 1 EA (;fi,# 300.00 = $300.00 11. Curb Ramp Installation 56 EA v( 2„600.00 = $145,600.00 12. Concrete Sidewalk Curb, 6,750 SF<<ry 8.00 = $54,000.00 and Gutter 13. Traffic Loop Installation 3 EA (ciy §i§.00 = $2,445.00 14. Accessibility 1 LS (? 1.00 = $1.00 GRAND TOTAL $1,938,009.75 AGREEMENT 2 V - Progress Payments (a). On not later than the 6th day of every month the Public Works Department shall prepare and submit an estimate covering the total quantities under each item of work that have been completed from the start of the job up to and including the 25th day of the preceding month, and the value of the work so completed determined in accordance with the schedule of unit prices for such items together with such supporting evidence as may be required by the City and/or Contractor . (b). On not later than the 15th day of the month, the City shall, after deducting previous payments made, pay to the Contractor 90% of the amount of the estimate as approved by the Public Works Department. (c). Final payment of all moneys due shall be made within 15 days after the expiration of 35 days following the filing of the notice of completion and acceptance of the work by the Public Works Department. (d). The Contractor may elect to receive 100% of payments due under the contract from time to time, without retention of any portion of the payment by the public agency, by depositing securities of equivalent value with the public agency in accordance with the provisions of Section 4590 of the Government Code. Such securities, if deposited by the Contractr, shall be valued by the City's Finance Director, whose decision on valuation of the securities shall be final. VI - Acceptance and Final Payment (a) Upon receipt of written notice that the work is ready for final inspection and acceptance, the Engineer shall within 5 days make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed, he will promptly issue a Notice of Completion, over his own signature, stating that the work required by this Contract has been completed and is accepted by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor by the City within 15 days after the expiration of 35 days following the date of recordation of said Notice of Completion. (b) Before final payment is due the Contractor shall submit evidence satisfactory to the Engineer that all payrolls, material bills, and other indebtedness connected with work have been paid, except that in case of disputed indebtedness or liens the Contractor may submit in lieu of evidence of payment a surety bond satisfactory to the City guaranteeing payment of all such disputed amounts when adjudicated in cases where such payment has not already been guaranteed by surety bond. (c) The Contractor shall provide a "Defective Material and Workmanship Bond" for 50% of the Contract Price, before the final payment will be made. (d) The making and acceptance of the final payment shall constitute a waiver of all claims by the City, other than those arising from any of the following: (1) unsettled liens; (2) faulty work appearing within 12 months after final payment; (3) requirements of the specifications; or (4) manufacturers' guarantees. It shall also constitute a waiver of all claims by the Contractor, except those previously made and still unsettled. (e) If after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, and the Engineer so certifies, the City shall, upon certificate of the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. AGREEMENT • 3 IN WITNESS WHEREOF, City and Contractor have caused their authorized representatives to execute this Agreement the day and year first written above. ATTEST: ,> � e • ige4-e-'e Esther Beime City Clerk CITY OF SARAFAEL: Albert Boro " Mayor �_. Stacy 1 AU011 e for.,.,, Brian O • . • Vice President AGREEMENT • 4 Premium is for Contract Term and is Subject Safeco Insurance Companies Safeco Plan to Adjustment Based on Final Contract Price Seatae, WA 98185 PERFORMANCE BOND Premium: $10,915.00 Bond 6581249 Issued In KNOW ALL BY THESE PRESENTS, That we, Ghilotti Construction Company, Inc. 246 Ghilotti Avenue, Santa Rosa, CA 95407 (hereinafter called the Principal), as Principal, and Safeco Insurance Company of America , a corporation duly organized under the laws of the State of Washington (hereinafter called the Surety), as Surety, arc held and fumly bound unto City of San Rafael 111 Morphew Street, San Rafael, CA 94915 , (hereinafter called the Obligee), in the sum of One Million Nine Hundred Thirty-eight Thousand Nine Dollars And Seventy-five Cents ($ 1,938,009.75 ) Dollars, for the payment of which sum well and truly to be made, we, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. Signed and sealed this 4th day of August 2008 WHEREAS, said Principal has entered into a written Contract with said Obligee, dated August 4, 2008 for Street Resurfacing 2007/2008 Project No. 11100 in accordance with the terms and conditions of said Contract, which is hereby referred to and made a part hereof as if fully set forth herein: NOW, THEREFORE, THE CONDITTON OF THIS OBLIGATION IS SUCH, That if the above bounden Principal shall well and truly keep, do and perform each and every, all and singular, the matters and things in said contract set forth and specifiers to be by said Principal kept, done and performed, at the times and in the manner in said contract specified, or shall pay over, make good and reimburse to the above named Obligee, all loss and damage which said Obligee may sustain by reason of failure or default on the pati of said Principal so to do, then this obligation shall be null and void; otherwise shall remain in full force and effect. NO SUIT, ACTION OR PROCEEDING by the Obligee to recover on this bond shall be sustained unless the same be commenced within two (2) years following the date on which Principal ceased work on said Contract. Ghilotti Construction Company, Inc. By Brian 04ar6 Vice President Safeco Insurance Company of America By Susan Fournier, A -in-Fact S-0757/SA 10/99 Safeco and the Safeco bgo are registered trademarks elSs!aro Corporation XDa State of California County of Placer On August 4, 2008 ACKNOWLEDGMENT before me, Kathy Rangel, Notary Public (insert name and title of the officer) personally appeared Susan Fournier who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. KA Y l-lY RANGEE XMIM #1547535 SACRAMENTO TO COUNTy Uri. IFxp, JAN, 27 2009 , Signature(Seal) " Y� Premium is for Contract Term and is Subject Safeco Insurance Companies hell v e'g safeco Place �l w , .: a to Adjustment Based on Final Contract Price Seattle, wa sales PAYMENT BOND Premium: Included BOND NO. 6581249 Issued In Duplicate KNOW ALL BY THESE PRESENTS, That we, Ghilotti Construction Company, Inc., 246 Ghilottl Avenue, Santa Rosa, CA 95407 (Here insert the name and address or legal title of Contractor) as Principal, hereinafter called Principal, and Safeco Insurance Company of America , a WA Corporation, as Surety, hereinafter called Surety, are held and firmly bound unto City of San Rafael, 111 Morphew Street, San Rafael, CA 94915 (Here insert the name and address or legal title of Owner) as Obligee, hereinafter called Owner, for the use and benefit of Claimants as herein defined, in the amount of One Million Nine Hundred Thirty-eight Thousand Nine Dollars And Seventy-five Cents Dollars (S 1,938,009.75 ), (Here insert a sum equal to at least one-half of the contract price) for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by written agreement dated August 4, 2008 entered into a contract with Owner for Street Resurfacing 2007/2008 - Project No. 11100 in accordance with the terms and conditions of said contract, which is hereby referred to and mode a part hereof. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, That if the Principal shall promptly make payment to all Claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the following conditions: 1. A Claimant is defined as one having a direct Contract with the Principal or with a Subcontractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the Contract. 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every Claimant as herein defused, who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such Claimant's work or labor was done or performed, or materials were famished by such Claimant, may sue on this bond for the use of such Claimant, prosecute the suit to final judgment for such sum or sums as may be justly due Claimant, and have execution thereon. 3. No suit or action shall be commenced hereunder by any Claimant. a) Unless Claimant, other than one having a direct Contract with the Principal, shall have given notice to any two of the following: The Principal, the Owner, or the Surety above named, within ninety (90) days after such Claimant did or performed the last of the work or labor, or furnished the last of (lie materials for which said claim is made. b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. c) Other tlsan in a state court of competent jurisdiction in and for the county or other political subdivision of the slate in which the Project, or any pari thereof, is situated, or in the United States District Court for the district in which the Project, or any part thereof, is situated, and not elsewhere, 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder. Signed and sealed this 4th day of August 1 2008 S4174/8A 2/99 Ghllottl Construction Company, Inc. By Brian gars Vice President Safeco Insurance Company of America Susan Fourier, m Atiomey-in-Fact Safeco and the Safeco logo are registered trademarks of Safeco Corporation XDP State of California County of Placer On August 4, 2008 ACKNOWLEDGMENT before me, personally appeared Susan Fournier Kathy Rangel, Notary Public (insert name and title of the officer) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. ' KA" fI Y RAN GEL ' r"`.• CDM. #1547535 SACRAMENTO C:ORyNTY c�Y��. Signature (Seal) POWER OF ATTORNEY KNOW ALL BY THESE PRESENTS: No. 13401 Safeco Insurance Company of America General Insurance Company of America Safeco Plaza Seattle, WA 98185 That SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA, each a Washington corporation, does each hereby appoint ********DONA LISA BUSCHMANN; J. BUSCHMANN; SUSAN FOURNIER, JANA B. PILGARD; KATHY RANGEL; ROBERT D. LAUX: Roseville, CA***-x-r*******,�***x+n Hs true and lawful atiomey(s}in-fact, with full authority to execute on its behalf fidelity and surety bonds or undertakings and other documents of a similar character issued in the course of its business, and to bind the respective company thereby. IN WITNESS WHEREOF, SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA have each executed and attested these presents this 16th day of June 1 2008 A+a,ou; STEPHANIE DA LEY WATSON,SECRETARY TIM MIKOLAJEWSKI SENIOR VICE-PRESIDENT SURETY CERTIFICATE Extract from the By -Laws of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA: "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer In charge of surety operations, shall each have authority to appoint individuals as attorneys -in -fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character Issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any Instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be Impressed or affixed or In any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, U) The provisions of Article V, Section 13 of the By -Laws, and (fi) A copy of the power-of-attorney appointment, executed pursuant thereto, and (fit) Certifying that said power-of-attomey appointment Is In full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, Stephanie Daley -Watson Secretary of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By -Laws and of a Resolution of the Board of Directors of these corporations, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both the By -Laws, the Resolution and the Power of Attorney are still In full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation this 4th II SEAL day of August ' 2008 STEPHANIE DALEY-WATSON, SECRETARY Safeco@ and the Safeco logo are registered trademarks of Safeco Corporation. 8 0974/DS 4/05 WEB PDF Company Profile Company Profile Company Search Company Search Results Company Information Old Company Names Agent for Service Reference Information NAIC Group List Lines of Business Company Performance & Comparison Data Financial Statements PDF's Annual Statements Quarterly Statements CA Supplements Company Complaint Company Enforcement Action Composite Complaints Studies Additional Info Find A Company Representative In Your Area Financial Rating Organizations View Financial Disclaimer COMPANY PROFILE Company Information Old Company Names SAFECO INSURANCE COMPANY OF AMERICA SAFECO PLAZA SEATTLE, WA 98185-0001 800-332-3226 Effective Date SELECTIVE AUTO & F INS CO AMER 11/02/1953 back to top Agent For Service JERE KEPRIOS C/O CT CORPORATION SYSTEM 818 WEST SEVENTH STREET, 2ND FLOOR LOS ANGELES CA 90017 back to top Reference Information NAIC #: 24740 California Company ID #: 1442-3 Date Authorized in California: 10/07/1953 License Status: UNLIMITED -NORMAL Company Type: Property & Casualty State of Domicile: WASHINGTON back to top NAIC Group List NAIC Group #: 0163 SAFECO INS GRP back to top Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary. AIRCRAFT AUTOMOBILE BOILER AND MACHINERY BURGLARY COMMON CARRIER LIABILITY CREDIT Page 1 of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Company Profile FIRE LIABILITY MARINE MISCELLANEOUS PLATE GLASS SPRINKLER SURETY TEAM AND VEHICLE WORKERS' COMPENSATION back to top 2008 California Department of Insurance Page 2 of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Best's Rating Center - Compaii— Information for Safeco Insurance Comr^ny of America Pagel of 2 Rating Center II I i r ), View Ratings: Financial Strength Issuer Credit $ec----- - Advanced _„Search Rating Methodology Industry Research Ratings Definitions Search Best's Ratings Press Releases Related Products i I Country Risk Structured Finance How to Get Rated Contact an Analvst Safeco Insurance Company of America (a member of Safeco Insurance companies) A.M.Best#:02448 NAIC #:24740 FEIN #: 910742148 Stock Ticker New York Stock Exchange NYSE SAF Address: Safeco, Plaza Seattle, WA 98185 Phone: 206-545-5000 Fax: 206-545-5500 Web: Www Safeco, corn Financial Strength Ratings view Definitions Rating: A (Excellent) Affiliation Code: p (Pooled) Financial Size Category: XV ($2 Billion or greater) Outlook: Positive Action: Affirmed Effective Date: April 23, 2008 Denotes Under Review.Best's_Ratngs Other Web Centers: Select One Va Print this page This rating Is assigned to Financial Strength Rating companies that have, in our opinion, an excellent ability to*. BE87 meet their ongoing obligations ' A Emcali•nt to policyholders. Issuer Credit Ratings View Definitions Long -Term: a+. Implication: Negative Action: Affirmed Under Review Date: April 23, 2008 Reports and News Visit our NewsRoom for the latest news,.and press releases for this company and its A.M. Best Group. AMB.,Credit Resort ,Insurance_ Professional_ (Unabridged) (formerly known as Best's Company Report) - includes Best's Financial Strength Rating and rationale along with comprehensive analytical commentary, detailed business overview and key financial data. Report Revision Date: 07107/2008 (represents the latest significant change). Historical Reports are available in AMB Credit Repoirt„_Insurance Professional (U.Iabildge.d.) Archv..e... Best's Executive Summary Reports (Financial Overview) - available in three versions, these presentation frr style reports feature balance sheet, income statement, key financial performance tests including profitability, liquidity and reserve analysis. Data Status: 2008 Best's Statement File - P/C, US. Contains data compiled as of 8/11/2008 (Quality Cross Checked). • Single Comoanv - five years of financial data specifically on this company. • Comparison - side-by-side financial analysis of this company with a peer group of up to five other companies you select. • Composite - evaluate this company's financials against a peer group composite. Report displays both the average and total composite of your selected peer group. AMB Credit; Report - Business Professional - provides three years of key financial data presented with !' colorful charts and tables. Each report also features the latest Best's Ratings, Ra ting Rationale and an excerpt from our Business Review commentary. Data Status: Contains data compiled as of 8/11/2008 (Quality Cross Checked). Bes_.t's Key Rating Guide Presentation Report - includes Best's Financial Strength Rating and financial data as provided in Best's Key Rating Guide products. Data Status: 2007 Financial Data (Quality Cross Checked). Financial and Analytical Products Bes„t's Property/Casu..alty Center Premium Data & Reports Best's Key Rating Guide - P/C,,, US & Canada Best's Statement File - P/G US Best's Statement File - Global Bests Insurance.Reports- P/G US, &,Canada Best's State Line - PIC. US Best's Insurance Expense Exhibit (IEE) . P/C, US Bests Schedule F (Reinsurance). P/Cn E.S.. Best's Schedule_ D iMunicipal Bonds) - US Best"s Schedule D (Common Stocks) - US Best"s Schedule D (Preferred Stock„s,) - US Best's, Schedule.P Loss Reserves) - P/C„ US Best's Schedule D _,Hybrid - P/C ,& IL/H, US Best"s Schedule D Cor_pprate Bonds), - U„S http://www3.ambest.com/ratings/FullProfile.asp?B1=0&AMBNum=2448&A1tSrc=1 &Alt... 8/19/2008 ACORD. CERTIFICATE OF LIABILITY INSURANCET—DATE 8 7/200 PRODUCER Woodruff -Sawyer & Co. 220 Bush St., 7th Floor San Francisco CA 94104 (415) 391-2141 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIC # INSURED Ghilotti Construction Company, Inc. . 246 Ghilotti Avenue Santa Rosa, CA 95407 INSURER A: National Union Fire Insurance Company of Pittsburgh PA 19445 INSURER B: Old Republic General Insurance Corporation 24139 INSURER c' INSURER D: INSURER E: r_AVFRAr.FS THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FORTHE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR A0131 POUCY NUMBER POUCYEFFECTNE POUCYEXPIRATION LIMITS B X GENERALUABIIJTY X COMMERCIAL GENERAL LIABILITY CLAIMS MADE a OCCUR AICG37540804 03/31/2008 03/31/2009 EACH OCCURRENCE s 2,000,000 PREMISES (Ea oopurenos) $ 100,000 MED EXP one $ 5.0 PERSONAL b ADV INJURY S 2,000,000 GENERALAGGREGATE $ 4,000,000 GEN'LAGGREGATEUMITAPPUESPER: PRODUCTS -COMPIOPAGG $ 2,000,000 POLICY X PRD- LOC B AUTOMOBILEIJABILTTY X ANY AUTO AlCA37540804 03/31/2008 03/31/2009 COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) BODILY INJURY S (Per peen) ALL OWNED AUTOS SCHEDULED AUTOS BODILY INJURY (Par �eM) $ X HIREDAUTOS NON -OWNED AUTOS PROPERTY DAMAGE $ (Per accident) GARAGEUABILTTY AUTO ONLY -EA ACCIDENT S OTHER THAN EA ACC S ANY AUTO AUTO ONLY: AGG $ A EXCESSIUMBRM.ALIABILTTY X OCCUR EICLAIMS MADE BE2858780 03/31/2008 03/31/2009 EACH OCCURRENCE s 3,000,000 AGGREGATE $ 3,000,000 S S DEDUCTIBLE $ RETENTION s WORKERS COMPENSATION AND WC STATH- N• 0E EMPLOYERS' UABLITY ANY PROPRIETORIPARTNERIEXECUTNE E.L. EACH ACCIDENT $ EL DISEASE -EAEMPLO S OFFICEIMEMBEREXCLUDED? IT yes, describe under SPECIAL PROVISIONS below E.L DISEASE - POLICY LIMIT S OTHER a a S -LL DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS GCC job #5244, Street Resurfacing 2007/2008, Project #11100. It is herby understood & agreed that the City of San Rafael, its officers, agents and employees are additional insured hereunder but only as respects liability arising out of the land and/or property and/or work described in the Public Works contract for the project entitled, Street Resurfacing 2007/2008, Project No. 11100 between the City of San Rafael & Ghilotti Construction Company, Inc for the work & the improvements described herein, additional insured forms CG 20 37 07 04, CG 2010 07 04 attached. UCK I II-IGAI t MULtICK UANUELIALIUN tU Uay NDUCO ror Non-raymenT or rmmnrm City of San Rafael Department of Public Works PO Box 151560 San Rafael, CA 94515-1560 I LOAN #: ACORD 25120011DRI In ie - SHOULD ANY OFTHE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL *@(X�MMAIL 30 DAYS WRITrEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, AUTHORIZED REPRESENTATIVE CORPORATION 1988 IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the Issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25 NAMED INSURED: Ghilotti Construction Company, Inc. POLICY NUMBER: AlCG37540804 COMMERCIAL GENERAL LIABILITY CG 2010 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED -- OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Locations Of Covered Operations City of San Rafael GCC job #5244, Street Resurfacing 2007/2008, Project Department of Public Works #11100. It is herby understood & agreed that the City of San PO Box 151560 Rafael, its officers, agents and employees are additional San Rafael, CA 94515-1560 insured hereunder but only as respects liability arising out of the land and/or property and/or work described in the Public Works contract for the project entitled, Street Resurfacing 2007/2008, Project No. 11100 between the City of San Rafael & Ghilotti Construction Company, Inc for the work & the improvements described herein, additional insured forms CG 20 37 07 04, CG 2010 07 04 attached. Information required to complete this Schedule, if not shown above will be shown in the Declarations. A. Section II — Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; In the performance of your ongoing operations for the additional Insured(s) at the location(s) desig- nated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclu- sions apply. This insurance does not apply to "bodily injury" or "property damage" occurring after. 1. All work, including materials, parts or equip- ment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its in- tended use by any person or organization other than another contractor or subcontractor en- gaged in performing operations for a principal as a part of the same project. Additional Insured; The City of San Rafael, its elective and appointive Boards, Commissions, Officers, Agents and Employees CG 2010 07 04 © ISO Properties, Inc., 2004 Page 1 of 1 ❑ NAMED INSURED: Ghilotti Construction Company, Inc. POLICY NUMBER: AIC037540804 COMMERCIAL GENERAL LIABILITY CG 20 37 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Location And Description Of Completed Operations City of San Rafael GCC job #5244, Street Resurfacing 2007/2008, Project #11100. It is Department of Public Works herby understood & agreed that the City of San Rafael, its officers, PO Box 151560 agents and employees are additional insured hereunder but only as San Rafael, CA 94515-1560 respects liability arising out of the land and/or property and/or work described in the Public Works contract for the project entitled, Stree Resurfacing 2007/2008, Project No. 11100 between the City of San Rafael & Ghilotti Construction Company, Inc for the work & the improvements described herein, additional insured forms CG 20 37 07 04, CG 20 10 07 04 attached Information required to complete this Schedule if not shown above will be shown in the Declarations. Section II -- Who Is An Insured is amended to in- clude as an additional insured the person(s) or or- ganizations) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" Mused, in whole or in part, by "your work" at the location designated and described in the schedule of this endorsement performed for that ad- ditional insured and Included in the "products -com- pleted operations hazard". Additional Insured; The City of San Rafael, its elective and appointive Boards, Commissions, Officers, Agents and Employees CG 20 37 07 04 Copyright, ISO Properties, Inc., 2004 Page 1 of 1 UNIFORM AGO RDCERTIFICATE OF LIABILITY INSURANCE ° 08/07/20 s PRODUCER Woodruff -Sawyer & Co. 220 Bush St., 7th Floor THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. San Francisco CA 94104 (415) 391-2141 INSURERS AFFORDING COVERAGE NAIC # INSURED Ghilotti Construction Company, Inc. 246 Ghilotti Avenue Santa Rosa, CA 95407 INSURER A. Old Republic General Ins=ce Corporation 24139 INSURER B: INSURER c INSURER D: INSURER E PREMISES a $ rnVFRAGFS THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR WpOLICYNUMBER R TYPROF INSURANCE POLICYEFFECTIVE POLICYEXPIRATIONLTR LIMITS GENERAL LIABILITY EACH OCCURRENCE S PREMISES a $ COMMERCIAL GENERAL LIABILITY MED EXP one S CLAIMS MADE F] OCCUR PERSONAL BADVINJURY S GENERAL AGGREGATE $ GEN -L AGG REGATE LI MIT APPLI ES PER: PRODUCTS - COMP/OP AGG $ POLICY PRO- L]LOC AUTOMOBILE LIABILITY ANYAUTO COMBINED SINGLE LIMIT (Ea accident) $ BODILY INJURY (Per Person) $ ALL OWNED AUTOS SCHEDULED AUTOS BODILY INJURY (Per accident) $ HIRED AUTOS NON -OWNED AUTOS PROPERTYDAMAGE $ (Per accident) OARAGELIABILtTY AUTO ONLY -EA ACCIDENT $ OTHER THAN EA ACC $ ANY AUTO AUTO ONLY. AGG $ EXCESSIUMBRELLA LIABILITY EACH OCCURRENCE $ AGGREGATE $ OCCUR 0 CLAIMS MADE S S DEDUCTIBLE S RETENTION $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY AICW37540704 10/01/2007 10/01/2008 0TH X TORY LIMS ER IT EE.L.EACH ACCIDENT $ 11000,()00 ANY OFFICEORWEMBEREXCLUDED? E.L DISEASE-EAEMPLOYE S 1,000,000 L DISEASE -POLICY LIMIT $ 1,000,000 Ir yyeess,, describe under SPECIALPROVISIONS bekw I OTHER f S S DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS GCC job #5244, Street Resurfacing 2007/2006, Project #11100. City of San Rafael Department of Public Works PO Box 151560 San Rafael, CA 94515-1560 10 Day Notice for Non -Payment of Premium SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL * MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, I AUTHORM90 LOAN #: 25 (2001108) ID #: © ACORD CORPORATION 1988 IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or after the coverage afforded by the policies listed thereon. ACORD 25 (2001108) Company Profile Company Profile Company Search Company Search Results Company Information Old Company Names Agent for Service Reference Information NAIC Group List Lines of Business Company Performance & Comparison Data Financial Statements PDF's Annual Statements Quarterly Statements CA Supplements Company Complaint Company Enforcement Action Composite Complaints Studies Additional Info Find A Company Representative In Your Area Financial Rating Organizations View Financial Disclaimer COMPANY PROFILE Company Information NATIONAL UNION FIRE INSURANCE COMPANY OF PITTSBURGH, PA 70 PINE STREET NEW YORK, NY 10270 800-551-0824 Old Company Names back to top Agent For Service LAURA KARPEN 2730 GATEWAY OAKS DRIVE SUITE 100 SACRAMENTO CA 95833 back to top Reference Information Effective Date NAIC #: 19445 California Company ID #: 0131-3 Date Authorized in California: 11/28/1902 License Status: UNLIMITED -NORMAL Company Type: Property & Casualty State of Domicile: PENNSYLVANIA back to top NAIC Group List NAIC Group #: 0012 AMERICAN INTRNL GRP back to top Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary AIRCRAFT AUTOMOBILE BOILER AND MACHINERY BURGLARY COMMON CARRIER LIABILITY DISABILITY FIRE Pagel of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Company Profile LIABILITY MARINE MISCELLANEOUS PLATE GLASS SPRINKLER SURETY TEAM AND VEHICLE WORKERS' COMPENSATION back to top © 2008 California Department of Insurance Page 2 of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Best's Rating Center - Compamr Information for National Union Fire Inc Co Pittsburgh PA Page 1 of 1 Rating Center j f- I View Ratings: Financial Strength Issuer Credit Securities Advanced Search Other Web Centers: Select One Rating Methodology _ Industry Research Ratings Definitions > National Union Fire Ins Co Pittsburgh PA A Print this page Search Bests Ratings I (a member of 6.Ma,Tjee?x jnl¢:Mg.fiogae Gpoup ire) This rating Is assigned to F"ioamial Strength Rating Press Releases A.M.Best #:02361 NAIL #: 19445 FEIN #: 250007550 companies that have, inopinour 1. BEST Related Praduds Address: 70 Pine Street Phone: 212-770-7000 meei thea ongoisuperng obligations meet their ongoing ohliga0ons A+ Superior ► New York, NY 10270 web: www.aic.com to policyholders. Industry & Regional Country Risk Best's Ratings Structured Finance Financial Strength Ratings View Definitions Issuer Credit Ratings view Definitions How to Get Rated Rating: A+ (Superior) Long -Term: aa - Contact an Analyst Affiliation Code: p (Pooled) Outlook: Negative Financial Size Category: XV ($2 Billion or greater) Action: Affirmed Outlook Negative Date: May 28, 2008 Action: Affirmed Effective Date: May 28, 2008 I qBES;T *Denotes Under Review Best's RatingsReports and News Visit our NewsRoom for the latest news and press releases for this company and its A.M. Best Group. AMB Credit Report - Insurance Professional (Unabridged) (formerly known as Best's Company Report) - includes Best's Financial Strength Rating and rationale along with comprehensive analytical commentary, detailed business overview and key financial data. Report Revision Date: 07/17/2008 (represents the latest significant change). Historical Reports are available in AMB Credit Report - Insurance Professional (Unabridged) Archive. _ Best's Executive Summary Reports (Financial Overview) - available in three versions, these presentation n style reports feature balance sheet, income statement, key financial performance tests including profitability, liquidity and reserve analysis. Data Status: 2008 Best's Statement File - P/C, US. Contains data compiled as of 8/11/2008 (Quality Cross Checked). • Simla CoM pane - five years of financial data specifically on this company. • Comparison - side-by-side financial analysis of this company with a peer group of up to five other companies you select. • Composite - evaluate this company's financials against a peer group composite. Report displays both the average and total composite of your selected peer group. A......M....B...C....r...e...d...it Report - Business Professional - provides three years of key financial data presented with colorful charts and tables. Each report also features the latest Best's Ratings, Rating Rationale and an excerpt from our Business Review commentary. Data Status: Contains data compiled as of 8/11/2008 (Quality Cross Checked). Bests Key Rating Guide Presentation Retort - includes Best's Financial Strength Rating and financial data r, as provided in Best's Key Rating Guide products. Data Status: 2007 Financial Data (Quality Cross Chediked). Financial and Analytical Products Bgst's_P,rap"/Casualty Center- Prem€um,._Data &worts Besfs_J(ey Rating Guide - PIC „US&....Canad...a Best's Statement File-- P/C US ........_.... Be. . I........................... Best's.. Insurance Reicorts P/C.M US & Canada Best's...S....ta...te. Line ... -.,P/C. LYS Best'sInsuranceExense Exhibit IIEE- PIC, .,..,......... Best's Schedule F (Reinsurance) -PIC, U,s. . est..'s SctYedule.�MurniC..iP. p....B....o....n....d...$).-U....S Best's Schedule..D (Common Stook)_ -_US Best's Schedule..D (Ereferred Stocks).... -..US Best's„Schedule.P (,Lass.. Re serves).,- P/C., US Best's Schedule D Hybrid. P!C B.G,OH, US Best's. Schedule aorate.Bo.n.ds)...-.,US Customer Service I .P...roduct Sglip Tort I Mem.b...e...0 .C.....e....n....t...e...r I Contact Info I Careers About A.M. Best Site..,Map I Privac. Pollcy Secu.r.. I Terms of Use I Legal & Licensing Copyright @ 2008 A.M. Best Company, lnc. All rights reserved. A.M. Best Worldwide Headquarters, Ambest Road, Oldwick, New Jersey, 08858, U.S.A. http://www3.ambest.com/ratings/FullProfile.asp?Bl�mO&AMBNwn=2351 &A1tSrc=1 &Alt... 8/19/2008 Company Profile Company Profile Company Search Company Search Results Company Information Old Company Names Agent for Service Reference Information NAIC Group List Lines of Business Company Performance & Comparison Data Financial Statements PDF's Annual Statements Quarterly Statements CA Supplements Company Complaint Company Enforcement Action Composite Complaints Studies Additional Info Find A Company Representative In Your Area Financial Rating Organizations View Financial Disclaimer COMPANY PROFILE Company Information OLD REPUBLIC GENERAL INSURANCE CORPORATION 307 N MICHIGAN AVE 17TH FL CHICAGO, IL 60601-5382 800-331-5554 Old Company Names INTERNATIONAL BUSINESS & MERCANTILE REASSURANCE COMPANY MOTORISTS BENEFICIAL INSURANCE COMPANY back to top Agent For Service KAREN HARRIS 2730 GATEWAY OAKS DRIVE SUITE 100 SACRAMENTO CA 95833 back to top Reference Information Effective Date 12/14/2006 04/21/1982 NAIC #: 24139 California Company ID #: 1800-2 Date Authorized in California: 06/30/1965 License Status: UNLIMITED -NORMAL Company Type: Property & Casualty State of Domicile: 77][ILLINOIS back to top NAIC Group List NAIC Group #: 0150 OLD REPUBLIC GRP back to top Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary. AUTOMOBILE BOILER AND MACHINERY BURGLARY COMMON CARRIER LIABILITY DISABILITY Page 1 of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Company Profile FIRE LIABILITY MARINE MISCELLANEOUS PLATE GLASS SPRINKLER SURETY TEAM AND VEHICLE WORKERS' COMPENSATION back to top (�, 2008 California Department of Insurance Page 2 of 2 http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 8/19/2008 Best's Rating Center-'Compan— Information for Old Republic General Tr,urance Corp Page 1 of 1 Rating Center f -+b View Ratings: Financial Strength Issuer Credit Securities Advanced Search Ether Web Centers. SelectOne Rating Methodology Industry Research Ratings Definitions > Old Republic General Insurance Corp Ig Print this page Search Best's Ratings (a member of Old Reoublic Insurance Group) This rating Is assigned to Financia( Strength Rating Press Releases A.M.Best is: 62363 NAIC #: 24139 FEIN #: 366667575 companies that have, in our opinion, superior ability ti REST Related Products Address: 307 North Michigan Avenue Phone: 312-346-8100 i g meet their ongoing obligations A+ SapGdor ► Chicago, IL 60601 Fax: 312-762-4700 to policyholders. Industry 8 Regional Web: www oidrepublic.com Country Risk Best 's Ratings Structured Finance How to Get Rated Financial Strength Ratings View Definitions Issuer Credit Ratings view Definitions Contact Analyst Rating: A+ (Superior) Long -Term: aa - an Financial Size Category: VIII ($100 Million to $250 Million) Outlook: Negative Outlook: Negative Action: Affirmed Action: Affirmed Date: June 24, 2008 Effective Date: June 24, 2008 * Denotes Under..Review Best's. Ratings Reports and News KEF3� Visit our NewsRoom for the latestn..ews.andpr...a...ss._relle.a....s...es. for this company and its A.M. Best Group. • . AMB Credit Report -insurance Professional Unabrid ed) (formerly known as Best's Company Report) -includes Best's Financial Strength Rating and rationale along with comprehensive analytical commentary, detailed gN1lltltlArlr1'I� i, p➢.i business overview and key financial data, ) Report Revision Date: 06/24/2008 (represents the latest slgnlificant change). Historical Reports are available iln AMB,Credit Report Insuurance Professional (Unabridgaed,) Archive. Best's Executive Summary Reports (Financial Overview) - available in three versions, these presentation , l style reports feature balance sheet, income statement, key financial performance tests including profitability, liquidity and reserve analysis. Data Status: 2008 Best's Statement File - P/C, US. Contains data compiled as of 8/11/2008 (Quality Cross Checked). • Single Comlpanv -five years of financial data specifically on this company. is Comparison - side-by-side financial analysis of this company with a peer group of up to five other companies you select, • Composite - evaluate this company's financials against a peer group composite. Report displays both the average and total composite of your selected peer group. AMB Credit Report - Business Professional - provides three years of key financial data presented with 1w colorful charts and tables. Each report also features the latest Best's Ratings, Rating Rationale and an excerpt from our Business Review commentary. Data Status: Contains data compiled as of 8/11/2008 (Quarry Cross Checked). Best's Key Rating G...uide Presentation, iReport - includes Best's Financial Strength Rating and financial data as provided in Best's Key Rating Guide products. Data Status: 2007 Financial Data (Quality Cross Checked). Financial and Analytical Products Bests,P-miler //Casualty _glgar-prernium,Dala & Reports Bests..... Key ..Rating, Guide - P/C. US & Canada Best's: Statement File - P/C U.S Best's Statement File - Global .............._..................................................... _ B....e....s....t's,..InsuranceReport�_-„_P/C...,,.._U....S.. & Canada Bests State Line - P/C, _US Best's Insurance ,Expense Exhiiiit,(1,EF) -.PIC US. Best's Schedule F (Reinsurance) - P/C US Best's Schedule D (Municipal Bonds) - US Best's Schedule D (Common Stocks) US Best's Schedule P (Less Rgsgryes) P/C,_US Best's Schedule D (Corporate Bonds) - US Customer Service I Product import I M,gmber Center I Contact Info I Careers About A.M. Best I Site Map I Privacy Policy I Security I Terms of Use � Legal & Llcensinat Copyright © 2008 A.M. Best Company, Inc. All rights reserved. A.M. Best Worldwide Headquarters, Ambest Road, Oldwick, New Jersey, 08858, U.S.A. http://www3.ambest.com/ratings/FullProfile.asp?B1=0&AMBNum=2383&AItSrc=1 &Alt... 8/19/2008 N Y O U IL 0 c Q1 E (D Q a) 0 0 0 0 0 0 0 0 O 0 6 0 0 0 0 0 0 0 0 0 0 0 Vq 0 0 0 0 0 0 0 O O O O O O O O O O O O O d O O O n M O — O O O O V1 O O O O Vl u O M rl W oi lc ' o W. 00 n o o ^ ICL o ri -r o v v U ¢ C y U O O O O O d 0 O O O O O 0 0 0 0 0 0 0 0 U M c n V9 0 0 0 0 0 0 0 O O O O O 0 0 0 0 0 0 0 0 0 0 0'S O N O V 0 0 0 0 O O O O O c O O Gl O F W O O o M O Vl O O rl O Vl 0 0— hl O n o U z U o- M o 7 7 7 z M b 00 0 e O rl n C d 0. - Vn 'o 0 o c o 0 o vl o 0 0 0 0 0 0 0 0 a d O T Q.o Nncvl-10 ol OOOo vibOOovlzo n W � v v: O -1 0 0c o 0 0n n o g M N ni a o c 0 0 0 O O o vl 0 0 0 0 O O O b O 0 0 0 J C U fI9 O O OVA O h d n 0 0 0 0 O O O O Cl O b 0 FLj.onori o -o n o00o vai0no n - - o 7- u E z U: - o vl v'l vl vl N N M Vl -' 00 0 3�a O O O M O 0 0 O 0 0 0 0 0 0 0 0 0 0 0 CJ M 0 0 IJO^ O O 0 0 0 0 O O o 0 0 o O o t 0 0- 0= 0 7 0 0 0 0 0 0 0 0 0 0 0 v. -T : Vl O OO s{ Vl V Vl N o V'1 o Vl Cv O O O CJ cp 0 0 M 1D W ¢_ rl o M ri a �? n v oa m o n i � O o M o rn n o t EU us o0oa0no C. 0000 0000000000 P n F W:B O O M^ Val N N O Val 0�0 r r o O T 0 0 d' U IF O— n V '7 N h M M ^- M Vl ^ C, c O n O vl vl N f N (L d O O O O O O O o 0 0 0 a 0 Hg : O 0 0 0 0 0 0 vl 0 0 0 0 O O O o 0 0 o O v � O60t4vlbOd a 0000 00rd0o00 c a.0cc�vlMO c 0000 vio�00000 �+l 10 N 00 17 ^ lD — M N ? hl — vl M V' W Y' �a U CJ O O O O a 0 O CJ O O o 0 0 0 0 0 0 0 Cl 0 -q : o 0 0 0 0 0 C. 0 0 0 0 0 O o 0 Ca o d o 0 O b0 N rt O rl O M O C7 0 0 0 O O h O d rl O O o- 0 0 !s U o a^ N o c v T n n M M- o vw o 0 n' O o O n 0^ O Vi O d d Vl Vl 6 0 0 ° .-a : O O N N d V 0 n O-- n O 1D V O b d -7 c U n W<: O %C O Q^ %0. O Vl O n n W W .- rw M O C O G 7 �- F- O KJ m 'D a D Ol lD hl M- Vi Vl V N x p O oh Vl O V O O 0 0 0 0 0 0 0 0 0 0 0 0 e0 �y' 64 O o 0 Vl o t` O nO O O O 6 0 6 0 0 0 0 0 ua:ooarlow-o m - - -- M O M M M M hl hl — M Sw .0 ^ 00000 -ID O 0000 O O O O O O O o V. Iry O O O Vl O n 0 O 0 0 0 0 O o O b 0 0 0 o N .odb V;orio n obOO 000000001® O rl O O O- - o d vl 0 0 0 0 n W : O O l? lc vl hi O n %C c h n n O Il N o v^ O vl N .. d � F cw ly'ao0 oo vl0 0000 00000000 0 o O O O b 0 0 0 0 0 0 0 0 0 F" W a o vl M O^ O c O Cl a 0 O O O Cl O 0 0 0 z U: 0 O 0 o M M M M N hl hl O — O CD \p M Vl M O C% C, ul rl c M^ N u^ u W a F, 7 V1 VS B Q Q B Q Q Q Q Q U. Q Ln C z'..-1 .-1 0 V5 Vl V5 uj ul LU (tJ W W W W W rn W _] L r C � Q > d E a o o n T . G O d N N W O a'c C 7 es ° C7 rr a d .p P u .6 •u o L0 a. o u v c U v rn in a a.:z9 U2 �F-QUpu,F�« rr .ti titid 0i .o u.6uu < - v�Um Fz; STREETS TO BE RESURFACED Note: Streets are listed in alphabetical order and not in the order in which they would be resurfaced. ID Street From To 1 Bret Harte Road Brushwood Lane Altura Way 2 Fernwood Way Knight Drive End of street 3 Fifth Avenue H Street J Street 4 Foster Lane Pine Street Center Street 5 Francisco Blvd. East Irene Street Main Street 6 Front Street Medway Road End of Street 7 Hayes Street Third Street Latham Street 8 Jewell Street Hubbell Court Union Street 9 Knight Drive Alderwood Way Pt. San Pedro Road 10 Le Claire Court Nova Albion Way End of street 11 Lido Lane Canal Street End of street 12 Lindaro Street Anderson Drive Woodland Avenue 13 Market Street Tiburon Street Verdi Street 14 McCoy Road Pe alk End of street 15 Montecillo Road Trellis Drive Tamarack Drive 16 Simms Street Anderson Drive End of Street 17 Summit Avenue Deer Park Avenue City Limit 111 Morphew Street, P.O. Box 151560, San Rafael, CA 94915-1560 SAN RAFAEL CITY COUNCIL ROUTING SLIP INSTRUCTIONS: USE THIS FORM WITH EACH SUBMITTAL OF ORIGINAL CONTRACT, AGREEMENT, ORDINANCE, OR RESOLUTION BEFORE APPROVAL BY COUNCIL/AGENCY. FROM: Andrew J. Preston DATE: July 30, 2008 SRCC AGENDA ITEM NO. 9 DATE OF MEETING: August 4, 2008 TITLE OF DOCUMENT: Report to Mayor and City Council and Resolution awarding the Contract for "Street Resurfacing 2007/2008" to Ghilotti Construction Company, Inc. in an amount of $1,938,009.75. REEL p J�ED JUL 3 12008 DEPARTME HEAD (Signature) wy ATTORNEY (LOWER HALF OF FORM FOR APPROVALS ONLY) REVIEWED BY CITY MANAGER XPPROVED AS COUNCIL AGENDA ITEM NOT APPROVED REMARKS: TO: APPROVED AS TO F RM: CITY ATTO (Signatu File No. 16.06.64 x/2 -